HSAR 3052.217-95 Liability and insurance (USCG). Basic (Dec 2003)

As prescribed in USCG guidance at (HSAR) 48 CFR 3017.9000(a) and (b), this clause shall be included in sealed bid fixed-price solicitations and contracts for vessel repair, alteration, or conversion which are to be performed within the United States, its possessions, or Puerto Rico. Unless inappropriate, this clause should be included in 
negotiated solicitations and contracts to be performed outside the United States. The contracting officer may, in whole or in part (such as after incidents), increase the dollar amounts in the clause at (HSAR) 48 CFR 3052.217-95 (b)(6) and (c)(1) consistent with contract size, inflation, and other circumstances.

LIABILITY AND INSURANCE (DEC 2003) 

(a) The Contractor shall exercise its best efforts to prevent accidents, injury, or damage to all employees, persons, and property, in and about the work, and to the vessel or part of the vessel upon which work is done.

(b) Loss or damage to the vessel, materials, or equipment. (1) Unless otherwise directed or approved in writing by the Contracting Officer, the Contractor shall not carry insurance against any form of loss or damage to the vessel(s) or to the materials or equipment to which the Government has title or which have been furnished by the Government for installation by the Contractor. The Government assumes the risks of loss of and damage to that property.

  • (2) The Government does not assume any risk with respect to loss or damage compensated for by insurance or otherwise or resulting from risks with respect to which the Contractor has failed to maintain insurance, if available, as required or approved by the Contracting Officer.

    (3) The Government does not assume risk of and will not pay for any costs of the following:

    (4) As to any risk that is assumed by the Government, the Government shall be subrogated to any claim, demand or cause of action against third parties that exists in favor of the Contractor. If required by the Contracting Officer, the Contractor shall execute a formal assignment or transfer of the claim, demand, or cause of action.

    (5) No party other than the Contractor shall have any right to proceed directly against the Government or join the Government as a codefendant in any action.

    (6) Notwithstanding the foregoing, the Contractor shall bear the first $5,000 of loss or damage from each occurrence or incident, the risk of which the Government would have assumed under the provision of this paragraph (b).

      • (i) Inspection, repair, replacement, or renewal of any defects in the vessel(s) or material and equipment due to—

        (ii) Loss, damage, liability, or expense caused by, resulting from, or incurred as a consequence of any delay or disruption, willful misconduct or lack of good faith by the Contractor or any of its representatives that have supervision or direction of--

        • (A) Defective workmanship performed by the Contractor or its subcontractors;

          (B) Defective materials or equipment furnished by the Contractor or its subcontractors; or

          (C) Workmanship, materials, or equipment which do not conform to the requirements of the contract, whether or not the defect is latent or whether or not the nonconformance is the result of negligence.

          (A) All or substantially all of the Contractor's business; or

          (B) All or substantially all of the Contractor's operation at any one plant.

(c) Indemnification. The Contractor indemnifies the Government and the vessel and its owners against all claims, demands, or causes of action to which the Government, the vessel or its owner(s) might be subject as a result of damage or injury (including death) to the property or person of anyone other than the Government or its employees, or the vessel or its owner, arising in whole or in part from the negligence or other wrongful act of the Contractor, or its agents or employees, or any subcontractor, or its agents or employees.

  • (1) The Contractor's obligation to indemnify under this paragraph shall not exceed the sum of $300,000 as a consequence of any single occurrence with respect to any one vessel.

    (2) The indemnity includes, without limitation, suits, actions, claims, costs, or demands of any kind, resulting from death, personal injury, or property damage occurring during the period of performance of work on the vessel or within 90 days after redelivery of the vessel. For any claim, etc., made after 90 days, the rights of the parties shall be as determined by other provisions of this contract and by law. The indemnity does apply to death occurring after 90 days where the injury was received during the period covered by the indemnity.

(d) Insurance. (1) The Contractor shall, at its own expense, obtain and maintain the following insurance--

  • (2) The Contractor shall ensure that all subcontractors engaged on the work obtain and maintain the insurance required in paragraph (d)(1) of this clause.

    (3) Upon request of the Contracting Officer, the Contractor shall provide evidence of the insurance required by paragraph (d) of this clause.

      • (i) Casualty, accident, and liability insurance, as approved by the Contracting Officer, insuring the performance of its obligations under paragraph (c) of this clause.

        (ii) Workers Compensation Insurance (or its equivalent) covering the employees engaged on the work.

(e) The Contractor shall not make any allowance in the contract price for the inclusion of any premium expense or charge for any reserve made on account of self-insurance for coverage against any risk assumed by the Government under this clause.

(f) The Contractor shall give the Contracting Officer written notice as soon as practicable after the occurrence of a loss or damage for which the Government has assumed the risk.

  • (1) The notice shall contain full details of the loss or damage.

    (2) If a claim or suit is later filed against the Contractor as a result of the event, the Contractor shall immediately deliver to the Government every demand, notice, summons, or other process received by the Contractor or its employees or representatives.

    (3) The Contractor shall cooperate with the Government and, upon request, shall assist in effecting settlements, securing and giving evidence, obtaining the attendance of witnesses, and in the conduct of suits. The Government shall reimburse the Contractor for expenses incurred in this effort, other than the cost of maintaining the Contractor's usual organization.

    (4) The Contractor shall not, except at its own expense, voluntarily make any payments, assume any obligation, or incur any expense other than what would be imperative for the protection of the vessel(s) at the time of the event.

(g) In the event of loss of or damage to any vessel(s), material, or equipment which may result in a claim against the Government under the insurance provisions of this contract, the Contractor shall promptly notify the Contracting Officer of the loss or damage. The Contracting Officer may, without prejudice to any right of the Government, either--

  • (1) Order the Contractor to proceed with replacement or repair, in which event the Contractor shall effect the replacement or repair;

    (2) Decide that the loss or damage shall not be replaced or repaired and in that event, the Contracting Officer shall--

      • (i) The Contractor shall submit to the Contracting Officer a request for reimbursement of the cost of the replacement or repair together with whatever supporting documentation the Contracting Officer may reasonably require, and shall identify the request as being submitted under the Insurance clause of this contract.

        (ii) If the Government determines that the risk of the loss or damage is within the scope of the risks assumed by the Government under this clause, the Government will reimburse the Contractor for the reasonable allowable cost of the replacement or repair, plus a reasonable profit (if the work or replacement or repair was performed by the Contractor) less the deductible amount specified in paragraph (b) of this clause.

        (iii) Payments by the Government to the Contractor under this clause are outside the scope of and shall not affect the pricing structure of the contract, and are additional to the compensation otherwise payable to the Contractor under this contract; or

      • (i) Modify the contract appropriately, consistent with the reduced requirements reflected by the unreplaced or unrepaired loss or damage; or

        (ii) Terminate the repair of any part or all of the vessel(s) under the Termination for Convenience of the Government clause of this contract.

(End of clause)

Prime’s Interest;
C/R ✖ Time and Materials ✖ Vessels Repair ✔ 

52.209-10 Prohibition on Contracting with Inverted Domestic Corporations.

52.214-27 Price Reduction for Defective Certified Cost or Pricing Data—Modifications—Sealed Bidding.

52.215-10 Price Reduction for Defective Certified Cost or Pricing Data.

52.215-11 Price Reduction for Defective Certified Cost or Pricing Data—Modifications.

52.216-24 Limitation of Government Liability.

52.222-12 Contract Termination—Debarment.

52.222-17 Nondisplacement of Qualified Workers.

52.222-50 Combating Trafficking in Persons.

52.222-55 Minimum Wages Under Executive Order 13658.

52.228-1 Bid Guarantee.

52.228-8 Liability and Insurance—Leased Motor Vehicles.

52.232-27 Prompt Payment for Construction Contracts.

52.236-23 Responsibility of the Architect-Engineer Contractor.

52.242-3 Penalties for Unallowable Costs.

52.246-16 Responsibility for Supplies.

52.246-18 Warranty of Supplies of a Complex Nature.

52.246-19 Warranty of Systems and Equipment under Performance Specifications or Design Criteria.

52.246-21 Warranty of Construction.

52.247-21 Contractor Liability for Personal Injury and/or Property Damage.

52.247-22 Contractor Liability for Loss of and/or Damage to Freight other than Household Goods.

52.247-23 Contractor Liability for Loss of and/or Damage to Household Goods.

52.247-58 Loading, Blocking, and Bracing of Freight Car Shipments.

252.227-7019 Validation of Asserted Restrictions--Computer Software.

252.227-7037 Validation of Restrictive Markings on Technical Data.

252.239-7013 Obligation of the Government.

252.247-7007 Liability and Insurance.

252.247-7014 Demurrage.

252.247-7016 Contractor Liability for Loss or Damage.

1852.245-71 Installation-accountable Government Property.

1852.227-88 Government-furnished computer software and related technical data.

1852.228-70 Aircraft Ground and Flight Risk.

1852.228-71 Aircraft Flight Risks.

1852.228-76 Cross-Waiver of Liability for International Space Station Activities.

1852.228-78 Cross-Waiver of Liability for Science or Space Exploration Activities Unrelated to the International Space Station.

1852.228-80 Insurance — Immunity From Tort Liability.

1852.228-81 Insurance — Partial Immunity From Tort Liability.

1852.228-82 Insurance — Total Immunity From Tort Liability.

1852.236-73 Hurricane Plan.

1852.245-72 Liability for Government property furnished for repair or other services.

3052.209-71 Reserve Officer Training Corps and military recruiting on campus.

3052.217-93 Subcontracts (USCG).

3052.217-97 Discharge of liens (USCG).

3052.217-99 Department of Labor Safety and Health Regulations for ship repairing (USCG).

3052.217-100 Guarantee (USCG).

3052.222-70 Strikes or picketing affecting timely completion of the contract work.

3052.222-71 Strikes or picketing affecting access to a DHS facility.

5352.223-9001 Health and Safety on Government Installations

5152.225-5900 Arming Requirements and Procedures for Personal Security Services Contractors and Requests for Personal Protection

5152.225-5903 Compliance with Laws and Regulations

5152.228-5900 Government Liability for Non-Tactical Vehicles

5152.225-5902 Fitness for Duty and Medical/Dental Care Limitations

5152.225-5915 CONTRACTOR ACCOUNTABILITY AND PERSONNEL RECOVERY

552.211-76 Charges for Packaging , Packing, and Marking.

552.211-89 Non-Manufactured Wood Packaging Material for Export.

552.236-82 Subcontracts.

552.238-75 Price Reductions.

652.236-70 Accident Prevention.

1452.215-70 Release of Claims.

Working with a set of FAR clauses from an RFP or contract?

Try pasting them into our tool to instantly generate a risk profile, including the basic flow down recommendation.

Info

Works best with Chrome and Edge browsers!