Working with a set of FAR clauses from an RFP or contract?

Try pasting them into our tool to instantly generate a risk profile, including the basic flow down recommendation.

DFARS 252.219-7011 Notification to Delay Performance. Basic (Jun 1998)

As prescribed in 219.811-3(3), use the clause at 252.219-7011, Notification to Delay Performance, in solicitations and purchase orders issued under the PA cited in 219.800.
NOTIFICATION TO DELAY PERFORMANCE (JUN 1998) The Contractor shall not begin performance under this purchase order until 2 working days have passed from the date of its receipt. Unless the Contractor receives notification from the Small Business Administration that it is ineligible for this 8(a) award, or otherwise receives instructions from the Contracting Officer, performance under this purchase order may begin on the third working day following receipt of the purchase order. If a determination of ineligibility is issued within the 2-day period, the purchase order shall be considered canceled. (End of clause)
Large business ✖ Subcontractor ✖ 


Works best with Chrome and Edge browsers!